SHIP HARDWARE / VENT SPACE MODS

(i) This is a combined synopsis/solicitation for commercial items, prepared in accordance with the format in subpart 12.6 of the FAR and as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a separate written solicitation will not be issued. (ii) Solicitation number 70Z04018Q60715Y00 applies and is used as a Request For Quote (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-96, effective, 17 September 2017. (iii) It is anticipated that a competitive price purchase order shall be awarded as a result of this synopsis/solicitation. All responsible sources may submit a quotation, which if timely received, shall be considered by this agency. (iv) The U.S. Coast Guard, Surface Forces Logistics Center (SFLC) intends to award a Firm Fixed Price Purchase Order. Award will be made on an all or none basis and lowest acceptable price. (v) The United States Coast Guard Surface Forces Logistics Center has a requirement for the following items: ITEM 1: TERMINAL, TYPE "E", 5" DIAMETER, ADJUSTABLE ANGLE, W/ DAMPER TERMINAL, TYPE "E", 5" DIAMETER, ADJUSTABLE ANGLE, W/DAMPER AND WM SCREEN MATERIAL CRES MFR P/N JE-102E DWG FH 512-FV05-06-2016 ITEM NO. 43 (2 EACH) DWG FH 512-FV05-10-2016 ITEM NO. 21 (4 EACH) QTY: 6 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 2: TERMINAL, TYPE "E", 6" DIAMETER, ADJUSTABLE ANGLE, W/ DAMPER TERMINAL, TYPE "E", 6" DIAMETER, ADJUSTABLE ANGLE, W/DAMPER AND WM SCREEN MATERIAL CRES MFR P/N JE-102E DWG FH 512-FV05-06-2016 ITEM NO. 44 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 3: TERMINAL, TYPE "E", 7" DIAMETER, ADJUSTABLE ANGLE, W/ DAMPER TERMINAL, TYPE "E", 7" DIAMETER, ADJUSTABLE ANGLE, W/DAMPER AND WM SCREEN MATERIAL CRES MFR P/N JE-102E DWG FH 512-FV05-06-2016 ITEM NO. 45 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 4: TERMINAL, TYPE "E", 8" DIAMETER, ADJUSTABLE ANGLE, W/ DAMPER TERMINAL, TYPE "E", 8" DIAMETER, ADJUSTABLE ANGLE, W/DAMPER AND WM SCREEN MATERIAL CRES MFR P/N JE-102E DWG FH 512-FV05-06-2016 ITEM NO. 46 (2 EACH) DWG FH 512-FV05-10-2016 ITEM NO. 22 (4 EACH) QTY: 6 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 5: TERMINAL, TYPE "E", 14" DIAMETER, ADJUSTABLE ANGLE, W/DAMPER TERMINAL, TYPE "E", 14" DIAMETER, ADJUSTABLE ANGLE, W/DAMPER AND WM SCREEN MATERIAL CRES MFR P/N JE-102E DWG FH 512-FV05-06-2016 ITEM NO. 47 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 6: TERMINAL, TYPE "J", 27 X 12, 15DEGREE, W/WM SCREEN TERMINAL, TYPE "J", 27" X 12", 15DEGREE, W/WM SCREEN MATERIAL GALVANIZED STEEL MFR P/N JE-108 DWG FH 512-FV05-06-2016 ITEM NO. 115 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 7: DUCT, SPIRAL, 5" DIA, 22 GAUGE DUCT, SPIRAL, 5" DIA, 22 GAUGE MATERIAL GALVANIZED STEEL (2) 10 FT LENGTHS DWG FH 512-FV-05-06-2016 ITEM NO. 52 DWG FH 512-FV-05-10-2016 ITEM NO. 23 QTY: 20 FT UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 8: DUCT, SPIRAL, 6" DIA, 22 GAUGE DUCT, SPIRAL, 6" DIA, 22 GAUGE MATERIAL GALVANIZED STEEL (1) 10 FT LENGTHS DWG FH 512-FV-06-2016 ITEM NO. 53 QTY: 10 FT UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 9: DUCT, SPIRAL,7" DIA, 22 GAUGE DUCT, SPIRAL, 7" DIA, 22 GAUGE MATERIAL GALVANIZED STEEL (3), 10 FT LENGTHS DWG FH 512-FV-06-2016 ITEM NO. 54 DWG FH 512-FV-10-2016 ITEM NO. 24 QTY: 30 FT UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 10: DUCT, SPIRAL, 8" DIA, 22 GAUGE DUCT, SPIRAL, 8" DIA, 22 GAUGE MATERIAL GALVANIZED STEEL (11) 10 FT LENGTHS FH 512-FH-05-06-2016 ITEM NO. 55 DWG FH 512-FV-10-2016 ITEM NO. 25 QTY: 110 FT UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 11: DUCT, SPIRAL, 12" DIA, 22 GAUGE DUCT, SPIRAL, 12" DIA, 22 GAUGE MATERIAL GALVANIZED STEEL (1) 10 FT LENGTHS DWG FH 512-FV05-10-2016 ITEM NO. 26 QTY: 10 LP UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 12: ELBOW, 5" DIA., 45 DEGREE ELBOW, 5" DIA., 45 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-45-3 DWG FH 512-FH-05-06-2016 ITEM NO. 56 (1 EACH) DWG FH 512-FH-05-10-2016 ITEM NO. 27 (2 EACH) QTY: 3 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 13: ELBOW, 5" DIA., 90 DEGREE ELBOW, 5" DIA., 90 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-90-5 DWG FH 512-FH-05-10-2016 ITEM NO. 28 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 14: ELBOW, 6" DIA., 30 DEGREE ELBOW, 6" DIA., 30 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-30-2 DWG FH 512-FH-05-06-2016 ITEM NO. 57 (4 EACH) QTY: 4 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 15: ELBOW, 6" DIA., 90 DEGREE ELBOW, 6" DIA., 90 DEGREE MATERIAL GALVANIZED STEEL MFR P/N/ JE-90-5 DWG FH 512-FH-05-06-2016 ITEM NO. 58 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 16: ELBOW, 7" DIA., 15 DEGREE ELBOW, 7" DIA., 15 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-15-2 DWG FH 512-FH-05-06-2016 ITEM NO. 59 (3 EACH) ITEM NO. 62 (2 EACH) QTY: 5 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 17: ELBOW, 7" DIA., 30 DEGREE ELBOW, 7" DIA., 30 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-30-2 DWG FH 512-FH-05-06-2016 ITEM NO. 60 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 18: ELBOW, 7" DIA., 90 DEGREE ELBOW, 7" DIA., 90 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-90-5 DWG FH 512-FH-05-06-2016 ITEM NO. 61 (3 EACH) QTY: 3 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 19: ELBOW, 8" DIA., 15 DEGREE ELBOW, 8" DIA., 15 DEGREE MATERIAL GALVANIZED STEEL MFR JE-15-2 DWG FH 512-FH-05-06-2016 ITEM NO. 63 (2 EACH) DWG FH 512-FH-05-10-2016 ITEM NO. 29 (1 EACH) QTY: 3 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 20: ELBOW, 8" DIA., 30 DEGREE ELBOW, 8" DIA., 30 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-30-2 DWG FH 512-FH-05-06-2016 ITEM NO. 64 (4 EACH) DWG FH 512-FH-05-10-2016 ITEM NO. 30 (3 EACH) QTY: 7 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 21: ELBOW, 8" DIA., 45 DEGREE ELBOW, 8" DIA., 45 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-45-3 DWG FH 512-FH-05-06-2016 ITEM NO. 65 (6 EACH) QTY: 6 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 22: ELBOW, 8" DIA., 60 DEGREE ELBOW, 8" DIA., 60 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-60-3 DWG FH 512-FH-05-10-2016 ITEM NO. 31 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 22: ELBOW, 8" DIA., 60 DEGREE ELBOW, 8" DIA., 60 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-60-3 DWG FH 512-FH-05-10-2016 ITEM NO. 31 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 23: ELBOW, 8" DIA., 90 DEGREE ELBOW, 8" DIA., 90 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-90-5 DWG FH 512-FH-05-06-2016 ITEM NO. 66 (5 EACH) DWG FH 512-FH-05-10-2016 ITEM NO. 32 (9 EACH) QTY: 14 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 24: ELBOW, 8" DIA., 90 DEGREE ELBOW, 8" DIA., 90 DEGREE MATERIAL GALVANIZED STEEL MFR P/N JE-90-5 DWG FH 512-FH-05-06-2016 ITEM NO. 66 (5 EACH) DWG FH 512-FH-05-10-2016 ITEM NO. 32 (9 EACH) QTY: 14 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 25: ELBOW, 90 DEGREE, 3" VANE TURN, 9 1/4" X 5" 18 GAUGE ELBOW, 90 DEGREE, 3" VANE TURN, 9 1/4" X 5" 18 GAUGE MATERIAL GALVANIZED STEEL MFR P/N JE-116 MODEL 12 DWG FH 512-FV05-06-2016 ITEM NO. 111 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 26: ELBOW, 90 DEGREE, 3" VANE TURN, 6" X 8" 18 GAUGE ELBOW, 90 DEGREE, 3" VANE TURN, 6" X 8" 18 GAUGE MATERIAL GALVANIZED STEEL MFR P/N JE-116 MODEL 12 DWG FH 512-FV05-06-2016 ITEM NO. 117 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 27: SPOOL, 7" DIA., L=6, 7.65 LB SPOOL, 7" DIA., L=6, 7.65 LB MATERIAL STEEL MFR PN JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 67 (2) EACH QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 28: SPOOL, 8" DIA., L=6, 7.65 LB SPOOL, 8" DIA., L=6, 7.65 LB MATERIAL STEEL MFR PN JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 68 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 28: SPOOL, 8" DIA., L=6, 7.65 LB SPOOL, 8" DIA., L=6, 7.65 LB MATERIAL STEEL MFR PN JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 68 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 29: SPOOL, 8" DIA., L=8, 7.65 LB SPOOL, 8" DIA., L=8, 7.65 LB MATERIAL STEEL MFR P/N JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 69 (3 EACH) QTY: 3 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 30: SPOOL, 10" X 8" 2"RC, L=6, 7.65 LB SPOOL, 10" X 8" 2"RC, L=6, 7.65 LB MATERIAL STEEL MFR P/N JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 70 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 31: SPOOL, 32" X 15" 3"RC, L=6, 10.2 LB SPOOL, 32" X 15" 3"RC, L=6, 10.2 LB MATERIAL STEEL MFR P/N JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 71 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 32: SPOOL, 13" X 10" 2"RC. L=2, 20.4 LB SPOOL, 13" X 10" 2"RC. L=2, 20.4 LB MATERIAL STEEL MFR P/N JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 116 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 33: SPOOL, 15" X 8" 2"RC, L=3, 7.65 LB SPOOL, 15" X 8" 2"RC, L=3, 7.65 LB MATERIAL STEEL MFR P/N JE-159 DWG FH 512-FV05-06-2016 ITEM NO. 118 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 34: ELBOW, 90 DEGREE, 6" VANE TURN, 15" X 32", 16 GAUGE ELBOW, 90 DEGREE, 6" VANE TURN, 15" X 32", 16 GAUGE MATERIAL GALVANIZED STEEL MFR P/N JE-116 MODEL 12 DWG FH 512-FV05-06-2016 ITEM NO. 51 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 35: ELBOW, 90 DEGREE, 6" VANE TURN, 24" X 11", 16 GAUGE ELBOW, 90 DEGREE, 6" VANE TURN, 24" X 11", 16 GAUGE MATERIAL GALVANIZED STEEL MFR P/N JE-116 DWG FH 512-FV05-08-2016 ITEM NO. 37 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 36: ELBOW, 90 DEGREE, 6" VANE TURN, 24" X 25", 16 GAUGE ELBOW, 90 DEGREE, 6" VANE TURN, 24" X 25", 16 GAUGE MATERIAL GALVANIZED STEEL MFR P/N JE-116 DWG FH 512-FV05-08-2016 ITEM NO. 38 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 37: LATERAL, REDUCING, 45 DEGREE, 7" DIA X 5" DIA X 5" DIA LATERAL, REDUCING, 45 DEGREE, 7" DIA X 5" DIA X 5" DIA MATERIAL GALVANIZED STEEL MFR P/N JE-L1/45 DWG FH 512-FV05-10-2016 ITEM NO. 34 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 38: LATERAL,REDUCING, 45 DEGREE, 12" DIA X 8" DIA X 8" DIA LATERAL,REDUCING, 45 DEGREE, 12" DIA X 8" DIA X 8" DIA MATERIAL GALVANIZED STEEL MFR P/N JE-L1/45 DWG FH 512-FV05-10-2016 ITEM NO. 35 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 39: ACCESS, COVER, QUICK OPENING, 12" DIA., TYPE C ACCESS, COVER, QUICK OPENING, 12" DIA., TYPE C MATERIAL GALVANIZED STEEL MFR P/N JE-132 DWG FH 512-FV05-06-2016 ITEM NO. 48 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 40: ACCESS, COVER, BOLTED, 24" X 12" ACCESS, COVER, BOLTED, 24" X 12" MATERIAL GALVANIZED STEEL MFR P/N JE-158 DWG FH 512-FV05-06-2016 ITEM NO.49 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 41: ACCESS, COVER, QUICK OPENING, 18 X 9, HINGELESS, UNINSULATED ACCESS, COVER, QUICK OPENING, 18" X 9", HINGELESS, UNINSULATED MATERIAL GALVANIZED STEEL, SPEC QQ-S-775 MFR P/N JE-125 DWG FH 512-FV05-08-2016 ITEM NO. 34 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 42: ACCESS, COVER, QUICK OPENING, 18 X18, HINGELESS, UNINSULATED ACCESS, COVER, QUICK OPENING, 18" X 18", HINGELESS, UNINSULATED MATERIAL GALVANIZED STEEL, SPEC QQ-S-775 MFR P/N JE-125 DWG FH 512-FV05-08-2016 ITEM NO. 35 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 43: ACCESS, COVER, BOLTED, 12" DIA ACCESS, COVER, BOLTED, 12" DIA MATERIAL GALVANIZED STEEL MFR P/N JE-158 DWG FH 512-FV05-08-2016 ITEM NO. 36 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 44: ACCESS COVER, QUICK ACTING, 6" DIA, NWT ACCESS COVER, QUICK ACTING, 6" DIA, NWT MATERIAL GALVANIZED STEEL MFR P/N JE-130 DWG FH 512-FV05-10-2016 ITEM NO. 73 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 45: ACCESS COVER, QUICK ACTING, 8" DIA, NWT ACCESS COVER, QUICK ACTING, 8" DIA, NWT MATERIAL GALVANIZED STEEL MFR JE-131 DWG FH 512-FV05-10-2016 ITEM NO. 74 (3 EACH) QTY: 3 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 46: ACCESS COVER, WATERTIGHT, 8" DIA, BOLTED ACCESS COVER, WATERTIGHT, 8" DIA, BOLTED MATERIAL ZINC COATED STEEL MFR P/N JE-158 DWG FH 512-FV05-10-2016 ITEM NO. 75 (4 EACH) QTY: 4 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 47: DOOR, CLOSURE, WEATHER-TIGHT, 18 X 11 CLEAR OPENING DOOR, CLOSURE, WEATHER-TIGHT, 18" X 11" CLEAR OPENING MATERIAL STEEL MFR P/N JE-150 DWG FH 512-FV05-06-2016 ITEM NO. 50 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 48: DOOR, CLOSURE, WEATHER-TIGHT, 21 X 11 CLEAR OPENING DOOR, CLOSURE, WEATHER-TIGHT, 21" X 11" CLEAR OPENING MATERIAL STEEL MFR P/N JE-150 DWG FH 512-FV05-10-2016 ITEM NO. 69 (1 EACH) QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 49: DAMPER, FIRE, 28 X 60, MULTI-LOUVER, 11GA. DAMPER, FIRE, 28" X 60", MULTI-LOUVER, 11GA. W/ MOTORIZED ACTUATORS MFR P/N MODEL MLD-100 DWG FH 512-FV05-08-2016 ITEM NO. 18 (2 EACH) FD 01-36-1 RIGHT HAND FD 01-36-2 LEFT HAND QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 50: DAMPER, BACKDRAFT, 25 X 21, VERTICAL DOWN DRAFT DAMPER, BACKDRAFT, 25" X 21", VERTICAL DOWN DRAFT P/N MODEL BD-1 DWG FH 512-FV05-08-2016 ITEM NO. 19 (1 EACH) BD 02-31-2 QTY: 1 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 51: SCREEN, WIRE MESH, 28" X 60", 1-1/2" U-BAR FRAME, 2"X2" MESH SCREEN, WIRE MESH, 28" X 60", 1-1/2" U-BAR FRAME, 2"X2" MESH MATERIAL CRES P/N JE-111 DWG FH 512-FV05-08-2016 ITEM NO. 20 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 52: SPOOL, 8" DIA., L=6, 10.2 LB SPOOL, 8" DIA., L=6, 10.2 LB MATERIAL STEEL MFR PN JE-159 DWG FH 512-FV05-10-2016 ITEM NO. 36 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ ITEM 53: SPOOL, 8" DIA., L=8, 10.2 LB SPOOL, 8" DIA., L=8, 10.2 LB MATERIAL STEEL MFR P/N JE-159 DWH FH 512-FV05-10-2016 ITEM NO. 37 (2 EACH) QTY: 2 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 3/5/18 PROMISED DELIVERY DATE:______________________ NOTE: All items are to be individually packed, and marked in accordance with below instructions. MARKINGS: EACH CONTAINER OR BOX SHALL BE MARKED WITH: ITEM NAME, STOCK NO., MFG PART NO. CAGE, CONTRACT NO. AND QUANTITY OF SAME LINE ITEMS PACKED IN THE SAME SHIPPING CONTAINER, AND DATE IN PRINTED BLACK BLOCK LETTERS MIN 1" HIGH. IMPORTANT! EACH ITEM MUST BE INDIVIDUALLY PACKAGED IN ACCORDANCE WITH THE COAST GUARD "UNIT OF ISSUE". ACCEPTABLE METHOD OF THE PACKAGE IS COMMERCIAL PACKAGING, DEFINED AS THE WAY ITEMS ARE PACKAGED, SOLD, AND SHIPPED TO THE PUBLIC OVER THE COUNTER PROVIDING IT IS PACKAGED IAW COAST GUARD "UNIT OF ISSUE". QUANTITIES OF SMALLER ITEMS (BOLTS/SCREWS) CAN BE MULTI-PACKED PROVIDING IT'S CORRECTLY MARKED. OR CONTAINER PROVIDING THE MARKING CLEARLY DISPLAYS THE TOTAL QUANTITY PER PACKAGE AND THE CG UNIT OF ISSUE. MARKING REQUIREMENTS: ALL PACKAGES, BOXES OR CONTAINERS SHALL BE CLEARLY MARKED / LABELED IN CLEAR LETTERING WITH THE FOLLOWING NOMENCLATURE: COAST GUARD 13 DIGIT STOCK NUMBER, MFG PART NO., CAGE CODE (IF KNOWN), PURCHASE ORDER / CONTRACT NUMBER, UNIT OF ISSUE, QUANTITY AND ANY ADDITIONAL MARKING AS DIRECTED BY PROCUREMENT AGENT. **FAILURE TO COMPLY WITH ALL PACKAGING AND MARKING REQUIREMENTS WILL RESULT IN MATERIAL BEING RETURNED, AT VENDORS EXPENSE, FOR CORRECTION.** QUESTIONS PERTAINING TO THIS RFQ SHOULD BE DIRECTED TO: MARK SOLOMON at [email protected] (vi) PLACE OF DELIVERY: U.S. Coast Guard, Surface Forces Logistics Center, 2401 Hawkins Point Road, Bldg. 88 Receiving Rm., Baltimore, MD 21226. All deliveries are to be made Monday through Friday between the hours of 7:00 AM and 1:00 PM EST. PREPARATION FOR DELIVERY: All material shipped to the U.S. Coast Guard, Surface Forces Logistics Center, Bldg. 88, Receiving Room, 2401 Hawkins Point Road, Baltimore, MD. 21226, on this purchase order, must be accompanied by an itemized packing list securely attached to the outside of the package. All packing lists shall cite the Purchase Order Number with the package in such a manner as to provide identification. Material shall be packed for shipment in such manner as to afford adequate protection to the item against corrosion, deterioration, and physical damage during shipment to Surface Forces Logistics Center locations. Package shall all provide adequate protection for warehouse storage and multiple shipments. All packages shall have the Purchase Order Number, Stock number (if applicable) and Vendor name and Part Number clearly marked on the exterior of the package. All deliveries are to be made Monday through Friday between the hours of 7:00 A.M. and 1:00 P.M. *PLEASE NOTE - NEW RECEIVING HOURS* GOVERNMENT ACCEPTANCE: Acceptance will be made at destination by a Government representative. Acceptance will be contingent upon the representative's verification of no damage in transit, correctness and completeness of order. FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at http://farsite.hill.af.mil/. Number Title Date 52.212-1 INSTRUCTIONS TO OFFERORS JAN 2017 52.212-2 EVALUATION - COMMERCIAL ITEMS OCT 2014 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEMS NOV 2017 52.212-4 CONTRACT TERMS AND CONDITIONS JAN 2017 52.247-34 F.O.B. DESTINATION NOV 1991 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders. Commercial Items (Nov 2017) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015). (3) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553). (4) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). __ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)). __ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) __ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note). __ (5) [Reserved]. __ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). __ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). __ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note). __ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). __ (10) [Reserved]. __ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). __ (ii) Alternate I (Nov 2011) of 52.219-3. __ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a). __ (ii) Alternate I (Jan 2011) of 52.219-4. __ (13) [Reserved] __ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644). __ (ii) Alternate I (Nov 2011). __ (iii) Alternate II (Nov 2011). __ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). __ (ii) Alternate I (Oct 1995) of 52.219-7. __ (iii) Alternate II (Mar 2004) of 52.219-7. __ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)). __ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)). __ (ii) Alternate I (Nov 2016) of 52.219-9. __ (iii) Alternate II (Nov 2016) of 52.219-9. __ (iv) Alternate III (Nov 2016) of 52.219-9. __ (v) Alternate IV (Nov 2016) of 52.219-9. __ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). __ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)). __ (20) 52.219-16, Liquidated Damages. Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). __ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f). _X_ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). __ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). __ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). _X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X_ (26) 52.222-19, Child Labor. Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). _X_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). _X_ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246). __ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212). __ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). __ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). __ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). _X_ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). __ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627). __ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) __ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693). __ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693). __ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Oct 2015) of 52.223-13. __ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-14. __ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). __ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-16. _X_ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513). __ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693). __ (44) 52.223-21, Foams (Jun 2016) (E.O. 13693). __ (45)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a). __ (ii) Alternate I (JAN 2017) of 52.224-3. __ (46) 52.225-1, Buy American.Supplies (May 2014) (41 U.S.C. chapter 83). _X_ (47)(i) 52.225-3, Buy American.Free Trade Agreements.Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43. __ (ii) Alternate I (May 2014) of 52.225-3. __ (iii) Alternate II (May 2014) of 52.225-3. __ (iv) Alternate III (May 2014) of 52.225-3. __ (48) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). __ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). __ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). __ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). __ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). __ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). __ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _X_ (55) 52.232-33, Payment by Electronic Funds Transfer.System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (56) 52.232-34, Payment by Electronic Funds Transfer.Other than System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). __ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). __ (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017)(15 U.S.C. 637(d)(12)). __ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). __ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495). __ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). __ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards.Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment. Requirements (May 2014) (41 U.S.C. chapter 67). __ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services. Requirements (May 2014) (41 U.S.C. chapter 67). __ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). __ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). __ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). __ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records. Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause. (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17. (v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015) (vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246). (vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xi) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). (xii) __(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627). __(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627). (xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). (xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67). (xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989). (xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xvii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706). (xviii)(A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). (B) Alternate I (Jan 2017) of 52.224-3. (xix) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xx) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of clause) 52.246-2 - Inspection of Supplies -- Fixed-Price (Aug. 1996) (a) Definition. "Supplies," as used in this clause, includes but is not limited to raw materials, components, intermediate assemblies, end products, and lots of supplies. (b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering supplies under this contract and shall tender to the Government for acceptance only supplies that have been inspected in accordance with the inspection system and have been found by the Contractor to be in conformity with contract requirements. As part of the system, the Contractor shall prepare records evidencing all inspections made under the system and the outcome. These records shall be kept complete and made available to the Government during contract performance and for as long afterwards as the contract requires. The Government may perform reviews and evaluations as reasonably necessary to ascertain compliance with this paragraph. These reviews and evaluations shall be conducted in a manner that will not unduly delay the contract work. The right of review, whether exercised or not, does not relieve the Contractor of the obligations under the contract. (c) The Government has the right to inspect and test all supplies called for by the contract, to the extent practicable, at all places and times, including the period of manufacture, and in any event before acceptance. The Government shall perform inspections and tests in a manner that will not unduly delay the work. The Government assumes no contractual obligation to perform any inspection and test for the benefit of the Contractor unless specifically set forth elsewhere in this contract. (d) If the Government performs inspection or test on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties. Except as otherwise provided in the contract, the Government shall bear the expense of Government inspections or tests made at other than the Contractor's or subcontractor's premises; provided, that in case of rejection, the Government shall not be liable for any reduction in the value of inspection or test samples. (e) (1) When supplies are not ready at the time specified by the Contractor for inspection or test, the Contracting Officer may charge to the Contractor the additional cost of inspection or test. (2) The Contracting Officer may also charge the Contractor for any additional cost of inspection or test when prior rejection makes reinspection or retest necessary. (f) The Government has the right either to reject or to require correction of nonconforming supplies. Supplies are nonconforming when they are defective in material or workmanship or are otherwise not in conformity with contract requirements. The Government may reject nonconforming supplies with or without disposition instructions. (g) The Contractor shall remove supplies rejected or required to be corrected. However, the Contracting Officer may require or permit correction in place, promptly after notice, by and at the expense of the Contractor. The Contractor shall not tender for acceptance corrected or rejected supplies without disclosing the former rejection or requirement for correction, and, when required, shall disclose the corrective action taken. (h) If the Contractor fails to promptly remove, replace, or correct rejected supplies that are required to be removed or to be replaced or corrected, the Government may either (1) by contract or otherwise, remove, replace, or correct the supplies and charge the cost to the Contractor or (2) terminate the contract for default. Unless the Contractor corrects or replaces the supplies within the delivery schedule, the Contracting Officer may require their delivery and make an equitable price reduction. Failure to agree to a price reduction shall be a dispute. (i) (1) If this contract provides for the performance of Government quality assurance at source, and if requested by the Government, the Contractor shall furnish advance notification of the time -- (i) When Contractor inspection or tests will be performed in accordance with the terms and conditions of the contract; and (ii) When the supplies will be ready for Government inspection. (2) The Government's request shall specify the period and method of the advance notification and the Government representative to whom it shall be furnished. Requests shall not require more than 2 workdays of advance notification if the Government representative is in residence in the Contractor's plant, nor more than 7 workdays in other instances. (j) The Government shall accept or reject supplies as promptly as practicable after delivery, unless otherwise provided in the contract. Government failure to inspect and accept or reject the supplies shall not relieve the Contractor from responsibility, nor impose liability on the Government, for nonconforming supplies. (k) Inspections and tests by the Government do not relieve the Contractor of responsibility for defects or other failures to meet contract requirements discovered before acceptance. Acceptance shall be conclusive, except for latent defects, fraud, gross mistakes amounting to fraud, or as otherwise provided in the contract. (l) If acceptance is not conclusive for any of the reasons in paragraph (k) hereof, the Government, in addition to any other rights and remedies provided by law, or under other provisions of this contract, shall have the right to require the Contractor (1) at no increase in contract price, to correct or replace the defective or nonconforming supplies at the original point of delivery or at the Contractor's plant at the Contracting Officer's election, and in accordance with a reasonable delivery schedule as may be agreed upon between the Contractor and the Contracting Officer; provided, that the Contracting Officer may require a reduction in contract price if the Contractor fails to meet such delivery schedule, or (2) within a reasonable time after receipt by the Contractor of notice of defects or nonconformance, to repay such portion of the contract as is equitable under the circumstances if the Contracting Officer elects not to require correction or replacement. When supplies are returned to the Contractor, the Contractor shall bear the transportation cost from the original point of delivery to the Contractor's plant and return to the original point when that point is not the Contractor's plant. If the Contractor fails to perform or act as required in (1) or (2) above and does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure, the Government shall have the right by contract or otherwise to replace or correct such supplies and charge to the Contractor the cost occasioned the Government thereby. (End of Clause) Alternate I (Jul 1985). If a fixed-price incentive contract is contemplated, substitute paragraphs (g), (h), and (l) below for paragraphs (g), (h), and (l) of the basic clause. (g) The Contractor shall remove supplies rejected or required to be corrected. However, the Contracting Officer may require or permit correction in place, promptly after notice. The Contractor shall not tender for acceptance corrected or rejected supplies without disclosing the former rejection or requirement for correction, and when required shall disclose the corrective action taken. Cost of removal, replacement, or correction shall be considered a cost incurred, or to be incurred, in the total final negotiated cost fixed under the incentive price revision clause. However, replacements or corrections by the Contractor after the establishment of the total final price shall be at no increase in the total final price. (h) If the Contractor fails to promptly remove, replace, or correct rejected supplies that are required to be removed or to be replaced or corrected, the Government may either (1) by contract or otherwise, remove, replace, or correct the supplies and equitably reduce the target price or, if established, the total final price or (2) may terminate the contract for default. Unless the Contractor corrects or replaces the nonconforming supplies within the delivery schedule, the Contracting Officer may require their delivery and equitably reduce any target price or, if it is established, the total final contract price. Failure to agree upon an equitable price reduction shall be a dispute. * * * * * _X__52.204-7 -- System for Award Management (Oct 2016) (a) Definitions. As used in this provision- "Electronic Funds Transfer (EFT) indicator" means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. "Registered in the System for Award Management (SAM) database" means that- (1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into the SAM database; (2) The offeror has completed the Core, Assertions, and Representations and Certification, and Points of contact sections of the registration in the SAM database; (3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process. (4) The Government has marked the record "Active". "Unique entity identifier" means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers. (b) (1) By submission of an Offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation. (2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in the SAM database. (c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information: (1) Company legal business name. (2) Tradestyle, doing business, or other name by which your entity is commonly recognized. (3) Company physical street address, city, state and Zip Code. (4) Company mailing address, city, state and Zip Code (if separate from physical). (5) Company telephone number. (6) Date the company was started. (7) Number of employees at your location. (8) Chief executive officer/key manager. (9) Line of business (industry). (10) Company Headquarters name and address (reporting relationship within your entity). (d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. (e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation. (f) Offerors may obtain information on registration at https://www.acquisition.gov. (End of Provision) Alternate I (Jul 2013). As prescribed in 4.1105(a)(2), substitute the following paragraph (b)(1) for paragraph (b)(1) of the basic provision: (b) (1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the System for Award Management prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation. If registration prior to award is not possible, the awardee shall be registered in the System for Award Management within 30 days after award or before three days prior to submission of the first invoice, whichever occurs first. 52.213-3 -- Notice to Supplier (Apr 1984) This is a firm order ONLY if your price does not exceed the maximum line item or total price in the Schedule. Submit invoices to the Contracting Officer. If you cannot perform in exact accordance with this order, Withhold Performance, and notify the Contracting Officer immediately, giving your quotation. (End of Clause) 52.213-4 Terms and Conditions -- Simplified Acquisitions (Other Than Commercial Items) (Nov 2017) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.222-3, Convict Labor (June 2003) (E.O. 11755). (ii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (iii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (iv) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). (v) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553). (vi) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note)). (2) Listed below are additional clauses that apply: (i) 52.232-1, Payments (Apr 1984). (ii) 52.232-8, Discounts for Prompt Payment (Feb 2002). (iii) 52.232-11, Extras (Apr 1984). (iv) 52.232-25, Prompt Payment (Jan 2017). (v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013). (vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013) (vii) 52.233-1, Disputes (May 2014). (viii) 52.244-6, Subcontracts for Commercial Items (JAN 2017). (ix) 52.253-1, Computer Generated Forms (Jan 1991). (b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more). (ii) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold). (iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (May 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands). (iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more). (v) 52.222-36, Equal Employment for Workers with Disabilities (Jul 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States.) (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.) (vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more). (vii) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf.) (viii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts). (B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies). (ix) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia). (x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United states (the 50 States and the District of Columbia.)) (xi) 52.213-4, Terms and Conditions - Simplified Acquisitions (Other than Commercial Items). (xii) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities). (xiii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693) (Applies to contracts for products as prescribed at FAR 23.804(a)(1)). (xiv) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners). (xv) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program (FEMP) will be- (A) Delivered; (B) Acquired by the Contractor for use in performing services at a Federally-controlled facility; (C) Furnished by the Contractor for use by the Government; or (D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance). (xvi) 52.223-20, Aerosols (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices). (xvii) 52.223-21, Foams (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities). (xviii) 52.225-1, Buy American -Supplies (May 2014) (41 U.S.C. chapter 83) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition-- (A) Is set aside for small business concerns; or (B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000). (xix) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States). (xx) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information.) (xxi) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.) (xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. App.1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).) (2) Listed below are additional clauses that may apply: (i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) (Applies to contracts when the contractor of a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.) (ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000). (iii) 52.211-17, Delivery of Excess Quantities (Sep 1989) (Applies to fixed-price supplies). (iv) 52.247-29, F.o.b. Origin (Feb 2006) (Applies to supplies if delivery is f.o.b. origin). (v) 52.247-34, F.o.b. Destination (Nov 1991) (Applies to supplies if delivery is f.o.b. destination). (c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/52_000.htm (d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights -- (1) Within a reasonable period of time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided. (g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (End of Clause) 52.217-8 -- Option to Extend Services (Nov 1999) The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within ______ [insert the period of time within which the Contracting Officer may exercise the option]. (End of Clause) 52.217-9 -- Option to Extend the Term of the Contract (Mar 2000) (a) The Government may extend the term of this contract by written notice to the Contractor within _____ [insert the period of time within which the Contracting Officer may exercise the option]; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least ___ days [60 days unless a different number of days is inserted] before the contract expires. The preliminary notice does not commit the Government to an extension. (b) If the Government exercises this option, the extended contract shall be considered to include this option clause. (c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed ___________ (months)(years). (End of Clause) Questions regarding this Request For Quote need to be submitted in writing to the POC Mark Solomon (410-762-6106) via email at [email protected] no later than 20 DECEMBER 2017. Quotes are due by 0800 EST 29 DECEMBER 2017 to Mark Solomon at [email protected].